Army Corps of Engineers

In a recent opinion issued by the United States Court of Federal Claims, Meridian Engineering Company vs. The United States, a case argued by our firm, the Court ruled that a contract modification containing a release did not prevent the contractor from recovering further damages. The dispute involved a contract between Meridian and the U.S. Army Corps of Engineers for a flood-control project in Nogales, AZ. After entering into the contract, the Contracting Officer issued two contract modifications that compensated Meridian for government-caused delays related to an access ramp and surveys. As a result of the underlying delays, Meridian’s work was pushed into the yearly rainy season in southern Arizona, referred to as the “monsoon” season, and completion of the critical channel invert work was impacted by numerous flood events. Had it not been for the earlier access ramp and survey delays, the work would have been completed before the onset of the “monsoon” season.

Continue Reading